Terms and Conditions of Sales and Services
By accepting delivery of products or by engaging Gameroom Show and/or its employees (collectively “Seller”) on the services identified on an invoice, Statement of Work, or other Seller documentation, Customer agrees to be bound by and accepts these Terms and Conditions unless Customer and Seller have signed a separate agreement, in which case the separate agreement will govern.
Important Information About These Terms and Conditions
These Terms and Conditions constitute a binding contract between Customer and Seller and are referred to herein as either “Terms and Conditions” or this “Agreement.” Customer accepts these Terms and Conditions by making a purchase from or placing an order with Seller or shopping on any Seller Website or Mobile Application (each, a “Site”) or otherwise requesting products (the “Products”) or engaging Seller to perform any Services (as this and all capitalized terms are defined herein). These Terms and Conditions are subject to change without prior notice, except that the Terms and Conditions posted on a Site at the time Customer places an order or signs a Statement of Work will govern the order in question, unless otherwise agreed in writing by Seller and Customer.
Customer consents to receiving electronic records, which may be provided via a Web browser or e-mail application connected to the Internet. In addition, Internet connectivity requires access services from an Internet access provider. Contact your local access provider for details. Electronic signatures (or copies of signatures sent via electronic means) are the equivalent of written and signed documents.
No course of prior dealings between the parties and no usage of trade will be relevant to determine the meaning of these Terms and Conditions or any invoice, or any document in electronic or written form that is signed and delivered by each of the parties for the performance of Services (e.g., a “Statement of Work”). This Agreement contains the entire understanding of the parties with respect to the matters contained herein and supersedes and replaces in its entirety any and all prior communications and contemporaneous agreements and understandings, whether oral, written, electronic or implied, if any, between the parties with respect to the subject matter hereof.
Governing Law
These Terms and Conditions, any Statements of Work, the Services hereunder, and any sale of Products hereunder will be governed by the laws of the State of Florida, without regard to conflicts of laws rules. Any arbitration, enforcement of an arbitration or litigation will be brought exclusively in Duval County, Florida, and customer consents to the jurisdiction of the federal and state courts located therein, submits to the jurisdiction thereof and waives the right to change venue. Customer further consents to the exercise of personal jurisdiction by any such court with respect to any such proceeding. Except in the case of nonpayment, neither party may institute any action in any form arising out of these terms and conditions more than one (1) year after the cause of action has arisen. The rights and remedies provided under these Terms and Conditions are cumulative, are in addition to, and do not limit or prejudice any other right or remedy available at law or in equity.
Title; Risk of Loss
If Customer provides Seller with Customer’s carrier account number or selects a carrier other than a carrier that regularly ships for Seller, title to Products and risk of loss or damage during shipment pass from Seller to Customer upon delivery to the carrier (F.O.B. Origin, freight collect). For all other shipments, title to Products and risk of loss or damage during shipment pass from Seller to Customer upon delivery to the specified destination (F.O.B. Destination, freight prepaid and added).
Customers may order services (collectively, “Services”) from or through Seller from time to time. Where Services are ordered in a Statement of Work, each Statement of Work hereby incorporates these Terms and Conditions and constitutes a separate agreement with respect to the Services performed. Seller may execute a Statement of Work. In the event of an addition to or a conflict between any term or condition of the Statement of Work and these Terms and Conditions, these Terms and Conditions will control, except as expressly amended in the applicable Statement of Work by specific reference to this Agreement. Each such amendment will be applicable only with respect to such Statement of Work and not to future Statements of Work. Changes to the scope of the Services described in a Statement of Work will be made only in a writing executed by authorized representatives of both parties. Seller will have no obligation to commence work in connection with any such change, unless and until the change is agreed upon in that writing executed by both parties. All such changes to the scope of the Services will be governed by these Terms and Conditions and the applicable Statement of Work. Each Statement of Work may be signed in separate counterparts each of which shall be deemed an original and all of which together will be deemed to be one original.
Cooperation
In addition to any specific Customer duties set forth in any applicable Statement of Work, Customer agrees to cooperate with Seller in connection with performance of the Services by providing: (i) timely responses to Seller’s inquiries, and (ii) access to any information or materials reasonably requested by Seller which are necessary or useful as determined by Seller in connection with providing the Services. Customer acknowledges and agrees that the Services are dependent upon the completeness and accuracy of information provided by Customer and the knowledge and cooperation of the agents, employees or subcontractors (“Personnel”) engaged or appointed by Customer who are selected by Customer to work with Seller.
Payment
Orders are not binding upon Seller until accepted by Seller. Customer agrees to pay the total purchase price for the Products plus shipping and handling, including shipping charges that are billed to Seller as a result of using Customer’s carrier account number. Terms of payment are within Seller’s sole discretion. In connection with Services being performed pursuant to a Statement of Work, Customer will pay for the Services in the amounts and in accordance with any payment schedule set forth in the applicable Statement of Work. If no payment schedule is provided, Customer will pay for the Services as invoiced by Seller. Invoices are due and payable within the time period specified on the invoice, measured from the date of invoice, subject to continuing credit approval by Seller. Seller may issue an invoice to Customer. Seller may invoice Customer separately for partial shipments, and Seller may invoice Customer for all of the Services described in a Statement of Work or any portion thereof.
Customer agrees to pay interest on all past-due sums at the lower of one and one-half percent (1.5%) per month or the highest rate allowed by law. Customer will pay for, and will indemnify and hold Seller harmless from, any applicable sales, use, transaction, excise or similar taxes and any federal, state or local fees or charges (including, but not limited to, environmental or similar fees), imposed on, in respect of or otherwise associated with any Statement of Work, Products, or Services. Customer must claim any exemption from such taxes, fees, or charges at the time of purchase and provide Seller with the necessary supporting documentation.
In the event of a payment default, Customer will be responsible for all of Seller’s costs of collection, including, but not limited to, court costs, filing fees and attorneys’ fees. In addition, if payments are not received as described above, Seller reserves the right to suspend Services until payment is received. Customer hereby grants to Seller a security interest in the Products to secure payment in full. Customer authorizes Seller to file a financing statement reflecting such security interest. Except as otherwise specified on an applicable Statement of Work, Customer will reimburse Seller for all reasonable out-of-pocket expenses incurred by Seller in connection with the performance of the Services, including, but not limited to, travel and living expenses.
Warranties
Customer understands that Seller is not the manufacturer of the Products purchased by Customer hereunder. Seller hereby expressly disclaims all representations, warranties, conditions or covenants, either express or implied, related to Products, including, but not limited to, any warranty of title, accuracy, merchantability, or fitness for a particular purpose, or warranty of non-infringement. Customer expressly waives any claim that it may have against Seller based on any product liability or infringement or alleged infringement of any patent, copyright, trade secret or other intellectual property rights (each a “Claim”) with respect to any Product and also waives any right to indemnification from Seller against any such Claim made against Customer by a third party. Customer acknowledges that no employee, agent, or representative of Seller is authorized to make any representation or warranty on behalf of Seller that is not in this Agreement.
Seller expressly disclaims all representations, warranties, conditions or covenants, either express or implied (including without limitation, any express or implied warranties or conditions of fitness for a particular purpose, merchantability, durability, title, accuracy or non-infringement) arising out of or related to the performance or non-performance of any Services hereunder. Customer acknowledges that no employee, agent, or representative of Seller is authorized to make any representation or warranty on behalf of Seller that is not in this Agreement or in a Statement of Work expressly amending this Agreement.
Seller will not be responsible for and no liability shall result to Seller for any delays in delivery or in performance which result from any circumstances beyond Seller’s reasonable control, including, but not limited to, Product unavailability, carrier delays, delays due to fire, severe weather conditions, failure of power, labor problems, acts of war, terrorism, embargo, acts of God, or acts or laws of any government or agency. Any shipping dates or completion dates provided by Seller or any purported deadlines contained in a Statement of Work or any other document are estimates only.
Pricing Information; Availability Disclaimer
Seller reserves the right to make adjustments to pricing, Products and Service offerings for reasons including, but not limited to, changing market conditions, Product unavailability, and errors in advertisements. All orders are subject to Product availability and the availability of Personnel to perform the Services. Therefore, Seller cannot guarantee that it will be able to fulfill Customer’s orders. If Services are being performed on a time and materials basis, any estimates provided by Seller are for planning purposes only.
Limitation of Liability
Under no circumstances and notwithstanding the failure of essential purpose of any remedy set forth herein, will Seller no be liable for: (a) any incidental, indirect, special, punitive, or consequential damages including but not limited to, loss of profits, business, revenues, or savings, even if Seller has been advised of the possibilities of such damages or if such damages are otherwise foreseeable, in each case, whether a claim for any such liability is premised upon breach of contract, warranty, negligence, strict liability, or other theory of liability; (b) any claims, demands or actions against Customer by any third party; (c) any loss or claim arising out of or in connection with Customer’s implementation of any conclusions or recommendations by Seller based on, resulting from, arising out of or otherwise related to Products or Services; or (d) any unavailability of a Product. In the event of any liability incurred by Seller, the entire liability of Seller for damages from any cause whatsoever will not exceed the dollar amount paid by Customer for the Product(s) giving rise to the claim or the specific Services giving rise to the claim.
Termination
Either party may terminate performance of a Service or a Statement of Work for cause if the other party fails to cure a material default in the time period specified herein. Any material default must be specifically identified in a written notice of termination. After written notice, the notified party will, subject to the provision of warranties herein, have thirty (30) days to remedy its performance except that it will only have ten (10) days to remedy any monetary default. Failure to remedy any material default within the applicable time period provided for herein will give cause for immediate termination, unless such default is incapable of being cured within the time period in which case the defaulting party will not be in breach (except for Customer’s payment obligations) if it used its reasonable efforts to cure the default. In the event of any termination of the Services or a Statement of Work, Customer will pay Seller for all Services performed and expenses incurred up to and including the date of termination plus any termination fee if one is set forth in the applicable Statement of Work. In such event Customer will also pay Seller for any out-of-pocket demobilization or other direct costs resulting from termination. Upon termination, all rights and obligations of the parties under this Agreement will automatically terminate except for any right of action occurring prior to termination, payment obligations and obligations that expressly or by implication are intended to survive termination (including, but not limited to, limitation of liability, indemnity, confidentiality, or licensing of Work Product and this survival provision).
Arbitration
Any claim, dispute, or controversy (whether in contract, tort or otherwise, whether preexisting, present or future, and including, but not limited to, statutory, common law, intentional tort and equitable claims) arising from or relating to the Products, the Services, the interpretation or application of these Terms and Conditions, or any Statement of Work or the breach, termination or validity thereof, the relationships which result from these Terms and Conditions or any Statement of Work, or Seller’s advertising or marketing (collectively, a “Claim”) will be resolved, upon the election of any of Seller, Customer, or the third parties involved, exclusively and finally by binding arbitration. If arbitration is chosen, it will be conducted pursuant to the Rules of the American Arbitration Association. If arbitration is chosen by any party with respect to a Claim, neither Seller nor Customer will have the right to litigate that Claim in court or to have a jury trial on that Claim or to engage in pre-arbitration discovery, except as provided for in the applicable arbitration rules or by agreement of the parties involved. Further, Customer will not have the right to participate as a representative or member of any class of claimants pertaining to any Claim. Notwithstanding any choice of law provision included in these Terms and Conditions, this arbitration agreement is subject to the Federal Arbitration Act (9 U.S.C. §§ 1-16). The arbitration will take place exclusively in Jacksonville, Florida. Any court having jurisdiction may enter judgment on the award rendered by the arbitrator(s). Each party involved will bear its own cost of any legal representation, discovery or research required to complete arbitration. The existence or results of any arbitration will be treated as confidential. Notwithstanding anything to the contrary contained herein, all matters pertaining to the collection of amounts due to Seller arising out of the Products or Services will be exclusively litigated in court rather than through arbitration.
Refunds
No refunds shall be provided for Services of any kind. Refunds are only available for Products damaged in transit provided that Customer pays Seller for shipping and handling, agrees to Seller’s choice of shipping courier, pays for insurance valued at the full amount of the Products, and informs Seller of damage to Products within 48 hours after receipt of Products. Customer agrees to cooperate with Seller’s shipping courier for inspections of any kind such that Seller’s shipping courier may file an insurance claim. Seller will reimburse Customer within seven (7) business days after receiving reimbursement from Seller’s shipping courier’s insurance provider. In the event that Seller’s shipping courier determines that the damage to Products did not occur during transit, no refund shall be provided to Customer.
Miscellaneous
Seller may assign or subcontract all or any portion of its rights or obligations with respect to the sale of Products or the performance of Services or assign the right to receive payments, without Customer’s consent. Customer may not assign these Terms and Conditions, or any of its rights or obligations herein without the prior written consent of Seller. Subject to the restrictions in assignment contained herein, these Terms and Conditions will be binding on and inure to the benefit of the parties hereto and their successors and assigns. No provision of this Agreement or any Statement of Work will be deemed waived, amended, or modified by either party unless such waiver, amendment, or modification is in writing and signed by both parties. The relationship between Seller and Customer is that of independent contractors and not that of employer/employee, partnership, or joint venture. If any term or condition of this Agreement or a Statement of Work is found by a court of competent jurisdiction to be invalid, illegal, or otherwise unenforceable, the same shall not affect the other terms or conditions hereof or thereof or the whole of this Agreement or the applicable Statement of Work. Notices provided under this Agreement will be given in writing and deemed received upon the earlier of actual receipt or three (3) days after mailing if mailed postage prepaid by regular mail or airmail or one (1) day after such notice is sent by courier or facsimile transmission. Any delay or failure by either party to exercise any right or remedy will not constitute a waiver of that party to thereafter enforce such rights.
Legal Inquiries
Legal inquiries should be directed to our legal department at legal@gameroomshow.com.